Laserfiche WebLink
covered by existing building and construction trades collective bargaining agreements), office <br />and clerical employees. <br /> <br />2.4.3 This Agreement shall not apply to any work performed on or near or leading to the site <br />of work covered by this Agreement that is undertaken by state, county or other governmental <br />bodies or their contractors; or by public or private utilities or their contractors; or by the City or <br />its contractors for work not part of the scope of the Projects. Further, this Agreement shall not <br />be construed to prohibit or restrict the City or its employees from performing work on or around <br />the Project construction sites or from entering Project sites for any purposes deemed <br />necessary or appropriate by the City. <br /> <br />2.4.4 This Agreement shall not apply to the off-site maintenance of leased equipment or the <br />on-site supervision of such work. <br /> <br />2.4.5 In the event that the City becomes aware or is made aware that this Agreement or <br />portions thereof are inconsistent with the terms and conditions of any grant, loan, or contract <br />with any Federal, State, or regional agency or with the instructions or directions of an authorized <br />representative of a Federal, State or regional agency to which the City is applying for or has <br />received grant funds, the City shall notify the Council. Within 24 hours of notification, the parties <br />shall meet and confer to attempt to modify the Agreement to avoid the forfeiture of any funding <br />or to otherwise resolve the issue. Should the parties be unable to come to an accord, this <br />Agreement or any inconsistent provision shall be modified, subject to the approval of the City <br />Council, to remain in compliance with the requirements of the applicable funding source. <br /> <br />2.5 Termination, Suspension and/or Delay of Work: It is understood and agreed that the <br />City, at its sole option, may change, terminate, delay and/or suspend any and all portions of <br />Covered W ork at any time. Further, the City may prohibit some or all work on certain days or <br />during certain hours of the day to comply with applicable codes, laws or regulations, permits or <br />to accommodate the ongoing operations of the City's facilities and/or to mitigate the effects of <br />the ongoing Projects' work on the businesses and residents in the neighborhoods of the <br />Project sites; and/or require such other operational or schedule changes that may be deemed <br />necessary, in its sole judgment, to effectively maintain the primary purpose of the City's <br />facilities and to remain a good neighbor to the residents and businesses in the immediate area <br />of any Projects. In order to permit the Contractors and Unions to make appropriate scheduling <br />plans, the City will provide the affected Contractor with reasonable notice of any changes, <br />beyond what was stated in the bid documents, that it requires pursuant to this Section. <br /> <br />2.6 Work covered by this Agreement within the following craft jurisdictions shall be <br />performed under the terms of their National Agreements as follows: the NTL Articles of <br />Agreement, the National Stack/Chimney Agreement, the National Cooling Tower Agreement, <br />and the National Agreement of Elevator Constructors, and any instrument calibration work and <br />loop checking shall be performed under the terms of the UA/IBEW Joint National Agreement <br />for Instrument and Control Technicians, with the exception that Articles IV, XI and XII of this <br />Agreement shall apply to such work. <br /> <br />2.7 The parties are hereby notified that any Projects funded in whole or in part by HUD <br />Section 3 financial assistance must provide employment, registered apprenticeship, training, <br />contracting, or other economic opportunities to Section 3 residents and businesses in a <br />manner that is consistent with Section 3 of the Housing and Urban Development Act of 1968.