T & S Intermodal Maintenance NPSA 20230801

Home

2315 South Bascom Ave, 200 Campbell, CA 95008 408.377.3099 f 408.377.2189 B-796683 2 this estimate if required. It is the responsibility of the Owner to verify all materials within 3 days of delivery for damage and completeness per the bill of lading. After this time, acceptance of product as ordered shall be without claims. Only standard building products are provided by manufacturer. CONTRACTORS BOARD NOTICE “CSLB is the state consumer protection agency that licenses and regulates construction contractors. Contact CSLB for information about the licensed contractor you are considering, including information about disclosable complaints, disciplinary actions and civil judgments that are reported to CSLB. Use only licensed contractors. If you fi le a complaint against a licensed contractor within the legal deadline (usually four years), CSLB has authority to investigate the complaint. If you use an unlicensed contractor, CSLB may not be able to help you resolve your complaint. Your only remedy may be in civil court, and you may be liable for damages arising out of any injuries to the unlicensed contractor or the unlicensed contractor’s employees. For more information: VISIT CSLB’s website at www.cslb.ca.gov CALL CSLB at 1-800-321-CSLB (2752) WRITE CSLB at P.O. Box 26000, Sacramento, CA 95826” Our proposal is based on our Building Professional’s interpretation of the information given by you including state and local building codes and regulations as they apply to your product ordering. The end customer is responsible to obtain his own building permits and governmental approval as part of this proposal. AM Star Construction is not hired as the architect of record or engineer of record for this project. Additional engineering may be required by others to obtain governmental approval. It may become necessary, however, during the approval process by you and the governing code authorities to alter certain design criteria not clearly defined as applicable to your product. All engineering provided is for the use of AM Star Construction, Inc. alone for fabrication of components. All project designs shall be based on a Risk Category 2 with a default site class of “D” soil condition for engineering purposes. It is the end customer’s responsibility to verify all building codes and loads prior to engineering. Changes from these classifications will require a redesign which is not included. Any cost changes resulting from these alterations will be documented and billed on time and material or a signed change order in advance. Contractor shall not participate in prevailing wage, Certified Payroll requirements, or Davis Bacon Act and bill the following for T and M billings only: Project Manager $225 per hour, Superintendent $150 per hour, Foreman $95 per hour, Journeyman $85 per hour, Apprentice $75 per hour. Payment on a Time and Material basis shall be defined as reimbursement of all material, equipment, subcontract, standard labor rates, subsistence, and other costs plus a 30% office overhead charge. Allowances are not guaranteed prices rather minimum prices only for material, labor, equipment, subcontract and other in which final pricing shall be forthcoming on a T and M Basis or an approved change order if above allowance. Extensive pricing, design and selection assistance by Owner required by Project Manager shall be added to total cost of Allowance at $225 per hour plus any other costs. Concrete Anchor Rod Corrections installed by others shall be a minimum charge of $500 each. Remobilization shall be charged at a minimum of $1,000 per incident. Forklift use and idle time shall be billed out at $500 per day. Extended general conditions due to delay by others shall be determined on a time and material basis. Hindered site access and lack of site weatherization by others may increase erection by more than 50%. Any reference to arbitration in any document is to be omitted from this agreement. There is a 30% cancellation fee on each line item above including allowances and deposits are non-refundable. Owner will provide reasonable evidence that financial arrangements have been made to fulfill financial obligations within 3 days of signing this agreement and throughout the project upon written demand from Contractor. AM Star is not responsible for damage or theft of material once delivered to site whether installed or not. All material shortages and damages must be reported within 3 days from delivery by owner. After such time, it shall be determined all materials were delivered per bill of lading without damage. Excess materials are typical and the property of the Building Manufacturer or AM Star and are not refundable. These materials will either be disposed of at site dumpster provided by Owner or at the option of the Manufacturer or AM Star taken back. No attachment materials or custom shapes shall be provided by AM Star or Manufacturer. DocuSign Envelope ID: 7F7BA4FE-A377-4495-B797-3B8499FD1E12